Terms Of Service

TERMS OF SERVICE

Auramax Construction LLC
Effective Date: March 7, 2026

Welcome to the website of Auramax Construction LLC (“Auramax,” “Company,” “we,” “us,” or “our”). These Terms of Service (“Terms”) govern your access to and use of our website, digital platforms, online tools, communications, and any services provided by Auramax Construction LLC (collectively, the “Services”).

By accessing, browsing, or using this website or communicating with our Company through online forms, phone, email, or messaging services, you acknowledge that you have read, understood, and agree to be bound by these Terms and our Privacy Policy.

If you do not agree to these Terms, you must discontinue use of the website and Services immediately.

1. Company Information

Auramax Construction LLC is a licensed, bonded, and insured contractor operating in the State of Washington specializing in residential and commercial construction services including roofing, exterior restoration, and related construction work.

Primary Service Areas include but are not limited to:

• Yakima County
• Tri-Cities Region
• Central Washington
• Surrounding Washington State areas

2. Use of the Website

You agree to use this website only for lawful purposes and in accordance with these Terms.

Users agree not to:

• Violate any local, state, federal, or international law
• Attempt to gain unauthorized access to website systems or servers
• Attempt to interfere with website security features
• Submit false or misleading information through contact forms
• Use the website for spam, solicitation, or fraudulent purposes
• Upload malicious code, viruses, or harmful technology

Auramax Construction LLC reserves the right to restrict, suspend, or terminate access to the website or Services at our discretion if a violation of these Terms occurs.

3. Estimates, Inspections, and Project Proposals

Any inspection, quote, or estimate provided through:

• Website submissions
• Phone calls
• Email communications
• In-person inspections

is non-binding and subject to change until a written contract is signed by both parties.

Final project pricing may vary depending on factors including but not limited to:

• Roof size and pitch
• Structural conditions
• Material availability
• Labor requirements
• Insurance scope adjustments
• Unforeseen damage discovered during construction

Auramax Construction LLC reserves the right to revise estimates when necessary to reflect actual project conditions.

4. Insurance Restoration Projects

For projects involving insurance claims:

• Auramax Construction LLC does not act as a public adjuster.
• We assist homeowners in documenting damages and providing repair estimates.
• Final claim decisions are determined solely by the homeowner’s insurance provider.

Any insurance restoration work is subject to the terms of a separate Insurance Contingency Agreement signed by the homeowner.

Auramax Construction LLC is not responsible for:

• Claim denials
• Insurance payment delays
• Coverage limitations imposed by the insurance provider.

5. Scheduling and Service Availability

Appointments, inspections, and project start dates are scheduled based on:

• availability
• weather conditions
• project complexity
• safety considerations

Auramax Construction LLC reserves the right to:

• reschedule appointments
• delay work due to weather or safety risks
• decline service requests if project conditions are unsafe or outside our scope.

6. Payments and Billing

Payment terms are outlined in the project contract.

Typical payment structures may include:

• Initial deposits
• Insurance payment assignments
• Progress payments
• Final completion payments

Accepted payment methods may include:

• Cash
• Check
• Credit / debit card
• Electronic transfer
• Insurance proceeds where applicable

Failure to make payment according to contract terms may result in:

• project suspension
• late fees
• collection actions
• property lien rights as allowed by Washington State law.

7. Workmanship and Material Warranties

Auramax Construction LLC stands behind the quality of its workmanship.

Work may include:

• manufacturer warranties on materials
• workmanship warranties for installation services

Warranty coverage does not apply to damage caused by:

• extreme weather events
• natural disasters
• improper maintenance
• unauthorized repairs or modifications
• structural issues unrelated to roofing installation.

Full warranty details are provided in the signed project contract.

8. User-Submitted Content

By submitting reviews, testimonials, photos, videos, or feedback to Auramax Construction LLC through our website or other communication channels, you grant the Company a non-exclusive, royalty-free, worldwide license to use such content for:

• marketing
• advertising
• social media
• promotional materials

You represent that you have the legal right to share the submitted content.

9. Third-Party Links and Tools

Our website may contain links to third-party platforms such as:

• financing providers
• scheduling tools
• marketing platforms
• social media networks

Auramax Construction LLC is not responsible for the policies, content, or services of those third-party providers.

Use of third-party platforms is governed by their own terms and privacy policies.

10. Limitation of Liability

To the maximum extent permitted by law, Auramax Construction LLC and its owners, employees, contractors, and affiliates shall not be liable for any indirect, incidental, consequential, or special damages, including but not limited to:

• lost profits
• loss of business
• property damage unrelated to our work
• delays caused by weather or material shortages.

Our maximum liability for any claim shall not exceed the total amount paid to Auramax Construction LLC for the specific project giving rise to the claim.

11. Indemnification

You agree to defend, indemnify, and hold harmless Auramax Construction LLC and its officers, employees, subcontractors, and affiliates from any claims, damages, losses, or legal expenses arising from:

• your misuse of the website
• your violation of these Terms
• inaccurate information submitted through the website
• disputes arising from third-party services or contractors not affiliated with Auramax.

12. Intellectual Property

All content on this website, including but not limited to:

• logos
• text
• graphics
• photographs
• videos
• designs
• software

is the exclusive property of Auramax Construction LLC and protected under U.S. copyright and trademark laws.

No content may be reproduced, distributed, or used without written permission.

13. Website Disclaimer

This website and its content are provided “as is” and “as available.”

Auramax Construction LLC makes no guarantees regarding:

• uninterrupted website access
• accuracy of website content
• availability of online tools

Information provided on the website is for general informational purposes only and does not constitute professional construction advice.

14. Governing Law

These Terms are governed by the laws of the State of Washington.

Any disputes arising from these Terms or the use of our Services shall be resolved in the courts located in Yakima County, Washington.

Both parties agree to attempt good-faith negotiation or mediation before pursuing litigation.

15. Modifications to Terms

Auramax Construction LLC reserves the right to modify these Terms at any time.

Updated Terms will be posted on this website with a revised effective date.

Continued use of the website after updates constitutes acceptance of the revised Terms.

16. Contact Information

If you have questions regarding these Terms of Service, please contact:

Auramax Construction LLC
Washington Contractor License #: AURAMCL749C6

613 W 5th Street
Wapato, WA 98951

Phone: (509) 728-4548
Email: auramaxroofing@gmail.com